Introduction

Welcome to Urbanspace Builders. These Terms & Conditions (“Terms”) govern your use of our website [https://urbanspacebuilders.com/] and our services. By accessing or using our website or engaging our services, you agree to these Terms. If you do not agree, please do not use our website or services.

About Urbanspace Builders

Urbanspace Builders (“we”, “us”, or “our”) is a Chennai-based construction company providing residential building, interior design, renovation, and project management services. Our goal is to deliver high-quality construction solutions with transparency and professionalism.

Use of Our Website

You may use our website to learn about our services, view our projects, and contact us.
You must not use the website for illegal or unauthorized purposes. You agree not to damage, hack, or misuse the site in any way.
All content, including text, images, logos, and designs on this website, are the property of Urbanspace Builders or its licensors. You may not copy, modify, or distribute any material without our written consent.

Payments and Fees

All payments for our services must be made as agreed in our official quotation or proposal.
Payments should be made in Indian Rupees (₹) and are subject to applicable taxes such as GST.
If payment is delayed or incomplete, Urbanspace Builders reserves the right to pause work or charge interest on the overdue amount as permitted by law.
In case of cancellation by the client, fees for completed work and materials purchased will be payable.

Project Timelines

We always aim to complete projects within agreed timelines. However, factors like weather conditions, permit delays, or material shortages can affect delivery schedules.
We will keep clients informed of any changes in the project timeline and take necessary steps to minimize delays.

Site Access and Safety

Clients must provide proper site access, utilities, and permissions for construction activities.
Urbanspace Builders follows all safety standards and expects clients to ensure a safe working environment at the site.
We are not responsible for damages or injuries resulting from unsafe site conditions not under our control.

Changes and Modifications

If you request any change to the approved plan or design during the project, it may lead to additional costs or time extensions.
All modifications must be approved in writing before implementation.

Warranty and Quality

Urbanspace Builders ensures that all work is carried out using quality materials and professional workmanship.
Any defects reported within the warranty period mentioned in the agreement will be rectified, provided the issue is not caused by misuse or third-party interference.
Other than the stated warranty, we make no additional guarantees unless specified in writing.

Limitation of Liability

We are not responsible for indirect or consequential losses such as loss of profit, delays due to third parties, or damages caused by external factors.
Our total liability for any claim related to our services is limited to the total amount paid by the client for that specific project.

Termination

Either party may terminate the service agreement by giving written notice as per the terms agreed upon.
If a project is terminated by the client, Urbanspace Builders must be paid for all completed work, materials purchased, and any other costs incurred up to the termination date.
Upon termination, both parties must clear any pending dues immediately.

Governing Law

These Terms & Conditions are governed by the laws of India.
Any disputes shall be subject to the exclusive jurisdiction of the courts in Chennai, Tamil Nadu.
Both parties agree to attempt amicable settlement before seeking legal remedy.

Intellectual Property

All creative works, designs, and concepts developed by Urbanspace Builders remain our intellectual property unless otherwise agreed in writing.
We reserve the right to use completed project images for our marketing and portfolio purposes unless the client objects in writing.

Force Majeure

We shall not be held responsible for any delay or failure to perform our obligations due to events beyond our control such as natural disasters, strikes, pandemics, or government actions.

Amendments

Urbanspace Builders reserves the right to modify or update these Terms & Conditions at any time. Updates will be posted on this page, and the “Last Updated” date will be changed accordingly.

Contact Us

If you have any questions about these Terms & Conditions, please contact:
Urbanspace Builders
Address:No.17, Door No.D2, First Floor, 1st Street, Sowmiya Nagar, Perumbakkam, Chennai-600100.
Email: info@urbanspacebuilders.com
Phone: +91 91500 30450
Website: https://urbanspacebuilders.com/